The effectiveness of Microsoft Project in assessing extension of time under PAM 2006 standard form of contract
Time is equal to money; and it is applies in the construction industry where time is very important. Most of the standard form of contracts provide contractual clauses to ascertain time and money related to the scenarios while Extension of Time (EOT) is one of them. Under circumstance and delays,...
Saved in:
Main Authors: | , |
---|---|
Format: | Article |
Language: | English |
Published: |
IOP Publishing
2017
|
Subjects: | |
Online Access: | http://eprints.intimal.edu.my/1014/1/Suhaida_2017_IOP_Conf._Ser.%253A_Mater._Sci._Eng._271_012049.pdf http://eprints.intimal.edu.my/1014/ |
Tags: |
Add Tag
No Tags, Be the first to tag this record!
|
id |
my-inti-eprints.1014 |
---|---|
record_format |
eprints |
spelling |
my-inti-eprints.10142018-02-09T02:19:08Z http://eprints.intimal.edu.my/1014/ The effectiveness of Microsoft Project in assessing extension of time under PAM 2006 standard form of contract Suhaida @ Suhana, Kamarudin Nurul Aini Osman* Wong, Z. D.* TH Building construction Time is equal to money; and it is applies in the construction industry where time is very important. Most of the standard form of contracts provide contractual clauses to ascertain time and money related to the scenarios while Extension of Time (EOT) is one of them. Under circumstance and delays, contractor is allow to apply EOT in order to complete the works on a later completion date without Liquidated Damages (LD) imposed to the claimant. However, both claimants and assessors encountered problems in assessing the EOT. The aim of this research is to recommend the usage of Microsoft Project as a tool in assessing EOT associated with the standard form of contract, PAM 2006. A quantitative method is applied towards the respondents that consisted of architects and quantity surveyors (QS) in order to collect data on challenges in assessing EOT claims and the effectiveness of Microsoft Project as a tool. The finding of this research highlighted that Microsoft Project can serve as a basis to perform EOT tasks as this software can be used as a data bank to store handy information which crucial for preparing and evaluating EOT. IOP Publishing 2017 Article PeerReviewed text en http://eprints.intimal.edu.my/1014/1/Suhaida_2017_IOP_Conf._Ser.%253A_Mater._Sci._Eng._271_012049.pdf Suhaida @ Suhana, Kamarudin Nurul Aini Osman* and Wong, Z. D.* (2017) The effectiveness of Microsoft Project in assessing extension of time under PAM 2006 standard form of contract. IOP Conference Series: Materials Science and Engineering,, 271. ISSN 1757-8981 10.1088/1757-899X/271/1/012049 |
institution |
INTI International University |
building |
INTI Library |
collection |
Institutional Repository |
continent |
Asia |
country |
Malaysia |
content_provider |
INTI International University |
content_source |
INTI Institutional Repository |
url_provider |
http://eprints.intimal.edu.my |
language |
English |
topic |
TH Building construction |
spellingShingle |
TH Building construction Suhaida @ Suhana, Kamarudin Nurul Aini Osman* Wong, Z. D.* The effectiveness of Microsoft Project in assessing extension of time under PAM 2006 standard form of contract |
description |
Time is equal to money; and it is applies in the construction industry where time is
very important. Most of the standard form of contracts provide contractual clauses to ascertain
time and money related to the scenarios while Extension of Time (EOT) is one of them. Under
circumstance and delays, contractor is allow to apply EOT in order to complete the works on a
later completion date without Liquidated Damages (LD) imposed to the claimant. However,
both claimants and assessors encountered problems in assessing the EOT. The aim of this
research is to recommend the usage of Microsoft Project as a tool in assessing EOT associated
with the standard form of contract, PAM 2006. A quantitative method is applied towards the
respondents that consisted of architects and quantity surveyors (QS) in order to collect data on
challenges in assessing EOT claims and the effectiveness of Microsoft Project as a tool. The
finding of this research highlighted that Microsoft Project can serve as a basis to perform EOT
tasks as this software can be used as a data bank to store handy information which crucial for
preparing and evaluating EOT. |
format |
Article |
author |
Suhaida @ Suhana, Kamarudin Nurul Aini Osman* Wong, Z. D.* |
author_facet |
Suhaida @ Suhana, Kamarudin Nurul Aini Osman* Wong, Z. D.* |
author_sort |
Suhaida @ Suhana, Kamarudin Nurul Aini Osman* |
title |
The effectiveness of Microsoft Project in assessing extension of
time under PAM 2006 standard form of contract |
title_short |
The effectiveness of Microsoft Project in assessing extension of
time under PAM 2006 standard form of contract |
title_full |
The effectiveness of Microsoft Project in assessing extension of
time under PAM 2006 standard form of contract |
title_fullStr |
The effectiveness of Microsoft Project in assessing extension of
time under PAM 2006 standard form of contract |
title_full_unstemmed |
The effectiveness of Microsoft Project in assessing extension of
time under PAM 2006 standard form of contract |
title_sort |
effectiveness of microsoft project in assessing extension of
time under pam 2006 standard form of contract |
publisher |
IOP Publishing |
publishDate |
2017 |
url |
http://eprints.intimal.edu.my/1014/1/Suhaida_2017_IOP_Conf._Ser.%253A_Mater._Sci._Eng._271_012049.pdf http://eprints.intimal.edu.my/1014/ |
_version_ |
1644541363693289472 |
score |
13.160551 |